Visitor Center Drive Rehabilitation

Gettysburg National Military Park (GETT) PMIS 318370, Visitor Center Drive a) This acquisition is being conducted via the Small Business Administration. The North American Industrial Classification System (NAICS) code and the associated small business size standard are noted in clause 52.204-8 in section "K" of this solicitation. b) Estimated Price Range: Between $1,000,000 and $5,000,000 c) Refer to section "L" for information regarding a pre-proposal site visit. d) Information and requirements stated in sections "B" through "J" & attachments noted in section "J" apply to this solicitation and the subsequent contract. e) Refer to section "L" for proposal submittal requirements. f) This is currently an unfunded requirement with a high expectation that funds will be available. When and if funds become available a contract will be awarded at that time. GENERAL 1. Submit, at a minimum, an offer that conforms to the solicitation documents. By submission of an offer, the offeror unconditionally assents to the terms and conditions in this solicitation and in any solicitation attachments. Proposals offering alternative stipulations to the requirements of this solicitation will NOT be considered or accepted. 2. In accordance with FAR 36.209, all firms, prime contractors or subconsultants, involved in developing the design or specifications for this construction solicitation are not eligible and prohibited from receiving any part of this construction award. Proposals from or containing firms under these circumstances will not be considered for award. B. QUESTIONS Pre-proposal questions shall be submitted a minimum of 7 days prior to the due date and time for proposals. Submit questions only though email to both of the following: Contracting Officer, L.J. Gravelle, lj_gravelle@nps.gov Contract Specialist, Zaira Lupidi, Zaira_lupidi@nps.gov C. OFFER DUE DATE AND LOCATION 1. To be considered for award, proposals must be received no later than the date and time noted in Block 13.a of the SF1442 contained in this solicitation. Offerors are responsible for confirming their proposals are received by the due date and time. D. SUBMISSION REQUIREMENTS 1. Proposals shall be submitted via email. Proposals submitted via any means other than email shall not be accepted. 2. Proposals shall be sent to all of the following: a. Contracting Officer, L.J. Gravelle, lj_gravelle@nps.gov b. Contract Specialist, Zaira Lupidi, Zaira_lupidi@nps.gov c. CS_DSC_Proposal_Submission@nps.gov 3. Title subject line for all proposal submissions shall contain the solicitation number, Park-PMIS, and number of total emails, per the following example: Subj: 140P2020R0137, GETT-318370, email 1 of 3 4. Submit proposals in separate VOLUMES (I and II) in the FORMATS specified, containing CONTENTS required. Each volume shall be submitted in separate email attachments. 5. Size limits: a. Individual email attachments shall be no larger than 38 MB. b. Each email shall be no larger than 100 MB SOLICITATION NUMBER: 140P2022R0137 PARK - PMIS: 318370 PROJECT TITLE: Visitor Center Drive Offerors are required to submit, at a minimum, an offer that conforms to the solicitation documents with pricing for Base line items and all option line items. Failure to do so may render the proposal unacceptable. On lump-sum line items, provide the total price only. For all unit-priced line items, provide the unit price and the extended total price. If no specific line item exists for a portion of the work, include the costs in a related item. In case of error in calculation of extended prices, the unit price governs. In case of summation error, the total corrected amounts govern. Round totals & extended prices to whole dollars. Refer to section "H" of this solicitation for additional information regarding contract options The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 196 Notice to Proceed (NTP) The time stated for completion shall include final cleanup of the premises. SCHEDULE Submit your proposed construction schedule for THIS SPECIFIC PROJECT showing completion within the required period of performance contained in this solicitation with accompanying schedule narrative. Submit your schedule in MS Project Gantt Chart format; for evaluation purposes only assume a Notice to Proceed date of October 15, 2022; and include specific activities required for this project and a clear critical path with major milestones and applicable predecessor activities. In your accompanying narrative, explain schedule logic, critical path activities, and key considerations and constraints. There is no preprinted form for this submittal. *The value for this project is based on a financial range. The value is listed as the highest possible cost from the range provided by a stakeholder or official project document.

Division 11 -	Equipment, Play Field Equipment and Structures, Playground Equipment, Play Structures.
Division 31 -	Earthwork, Selective Clearing, Grading.
Division 32 -	Exterior Improvements, Operation and Maintenance of Exterior Improvements, Athletic and Recreational Surfacing, Site Improvements, Fences and Gates, Planting.
Division 33 -	Utilities.
Division 34 -	Transportation, Operation and Maintenance of Transportation.