2022 Striping Project

The project shall consist of restriping various county roads. All Striping shall comply with the 2021 FDOT Standard Specifications for Road and Bridge Construction Bid No. 22-05 Contracting Officer: Shandra Gainous For questions, please contact Justin Ford at (850) 674!3300 or jford@dewberry.com. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes. Completion date for this project will be 60 days from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $200.00 per day. Please indicate on the envelope that this is a sealed bid for "Bid No. 22-05, 2022 STRIPING PROJECT". The Bid will be awarded to the lowest responsive bidder. This advertisement is to run 14 days prior to bidding. The County reserves the right to accept or reject any and all bid and to waive any technicalities or irregularities therein. The County further reserves the right to award the agreement to that bidder whose bid best complies with the specifications. Bidders may withdraw their bid by notifying the County in writing at any time prior to the deadline for bid submittal. After the deadline, the bid will constitute an irrevocable offer for a period of sixty (60) days.

Division 09 -

Finishes.