New Moody Police Department

The Project new two-story building to house the City of Moody Police Department. The building contains approximately 15,000 square feet. The building is built with shallow footings, steel frame with some load bearing CMU, with brick veneer, and a single-ply TPO roof. The project will also include some site work and underground utilities to accommodate the new building. The official time will be determined by the Architect, or his designated representative. The proposals will be opened at this time at the location listed above. A cashier's check or Bid Bond payable to the City of Moody, Alabama in an amount of not less than five (5) percent of the amount of the proposal, but in no event more than $10,000 must accompany the bid. Performance and Statutory Labor and Material Payment Bonds in the amount of 100% of the Contract Price will be required at the signing of the Contract. All bidders must submit three (3) copies of their bids on proposal forms furnished by the Architect or copies thereof. All bidder bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama 1975 and must show evidence of license before bidding or the bid will not be received or considered by the Architect; the bidder shall show such evidence by clearly displaying his or her current license number on the outside of the sealed envelope in which the proposal is delivered. The successful bidder must provide evidence of enrollment in the E-verify program per The Alabama Immigration Law (also referred to as "Act 2011-535" and codified in state law as Title 31, Chapter 13 of the Code of Alabama 1975) and amended by Act No. 2012-491 (2012) before awarding of contract. The Owner reserves the right to reject any or all the proposals and waive technical errors if, in the Owner's judgement, the best interest of the Owner will thereby be promoted. The project is being bid EXCLUDING TAXES and requires the Contractor to comply with the requirements of Act 2013-205 which was signed into law May 19, 2013. The Contractor and Owner will be required to apply for Certificates of Exemption with the Alabama Department of Revenue which will handle the administration of the certificates. The contractor shall account for the tax savings on the Accounting of Sales Tax form included in the specifications behind the proposal form. Failure for the Contractor to complete this form and include with their proposal shall render the bid non-responsive. Performance Time: The project is a single-phase project and is to be complete within 395 calendar days from the Notice to Proceed. Liquidated damages apply to this project per the Supplementary Conditions.

Division 03 -	Concrete, Concrete Forming, Cast-in-Place Concrete.
Division 04 -	Masonry, Unit Masonry.
Division 05 -	Metals, Structural Metal Framing.
Division 06 -	Wood, Plastics, and Composites, Rough Carpentry, Finish Carpentry.
Division 07 -	Thermal and Moisture Protection, Dampproofing and Waterproofing, Thermal Protection, Weather Barriers.
Division 08 -	Openings, Metal Doors and Frames, Wood Doors, Plastic Doors, Specialty Doors and Frames, Panel Doors, Multi-Leaf Vertical Lift Doors.
Division 09 -	Finishes, Plaster and Gypsum Board, Tiling, Flooring, Acoustic Treatment, Painting, High-Performance Coatings.
Division 10 -	Specialties, Signage, Compartments and Cubicles, Toilet Compartments, Shower and Dressing Compartments, Toilet, Bath, and Laundry Accessories, Emergency Aid Specialties, Fire Protection Specialties, Lockers, Wardrobe and Closet Specialties, Flagpoles, Flags and Banners.
Division 11 -	Equipment, Unit Kitchens.
Division 12 -	Furnishings, Countertops, Rugs and Mats.
Division 14 -	Conveying Equipment, Slide Pole Systems, Firehouse Slide Poles.
Division 21 -	Fire Suppression, Facility Fire-Suppression Water-Service Piping, Fire-Department Connections, Fire Pumps.
Division 22 -	Plumbing, Instrumentation and Control for Plumbing, Facility Water Distribution, Facility Storm Drainage, Plumbing Equipment, Plumbing Fixtures, Emergency Plumbing Fixtures, Drinking Fountains and Water Coolers.
Division 23 -	Heating, Ventilating, and Air Conditioning (HVAC), Instrumentation and Control for HVAC, HVAC Piping and Pumps, HVAC Air Distribution.
Division 26 -	Electrical, Power Distribution Units, Interior Lighting, Emergency Lighting, Exit Signs, Exterior Lighting.
Division 27 -	Communications, Structured Cabling, Call Management, Distributed Audio-Video Communications Systems.
Division 28 -	Electronic Safety and Security, Electronic Detection and Alarm, Fire Detection and Alarm.
Division 31 -	Earthwork, Clearing and Grubbing, Grading, Soil Treatment.
Division 32 -	Exterior Improvements, Bases, Ballasts, and Paving, Flexible Paving, Asphalt Paving, Rigid Paving, Concrete Paving, Curbs, Gutters, Sidewalks, and Driveways.
Division 33 -	Utilities, Water Utilities, Sanitary Sewerage Utilities, Storm Drainage Utilities.