City of Alabaster - Thompson Football Stadium - Demolition

The Project consists of demolition of multiple buildings and the visitor stands at the existing Thompson High School Stadium. Work includes complete removal of several buildings including selective removal and capping of exisitng underground utilities. The work will include removal of concrete paving and curbing, and preparation of the site for future construction. New fencing to secure the area will be included. A cashier's check or Bid Bond payable to the City of Alabaster in an amount of not less than five (5) percent of the amount of the proposal, but in no event more than $10,000 must accompany the bid. Performance and Statuatory Labor and Material Payment Bonds in the amount of 100% of the Contract Price will be required at the signing of the Contract. All bidders must submit three (3) copies of their bids on proposal forms furnished by the Architect or copies thereof. All bidder bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama 1975 and must show evidence of license before bidding or the bid will not be received or considered by the Architect; the bidder shall show such evidence by clearly displaying his or her current license number on the outside of the sealed envelope in which the proposal is delivered. The successful bidder must provide evidence of enrollment in the E-verify program per The Alabama Immigration Law (also referred to as "Act 2011-535" and codified in state law as Title 31, Chapter 13 of the Code of Alabama 1975) and amended by Act No. 2012-491 (2012) before awarding of contract. The Owner reserves the right to reject any or all the proposals and waive technical errors if, in the Owner's judgement, the best interest of the Owner will thereby be promoted. The Owner reserves the right to reject any or all the proposals and waive technical errors if, in the Owner's judgement, the best interest of the Owner will thereby be promoted. The project is being bid EXCLUDING TAXES and requires the Contractor to comply with the requirements of Act 2013-205 which was signed into law May 19, 2013. The Contractor and Owner will required to apply for Certificates of Exemption with the Alabama Department of Revenue which will handle the administration of the certificates. The contractor whall account for the tax savings on the Accounting of Sales Tax form included in the specifications behind the proposal form. Failure for the Contractor to complete this form and include with their proposal shall render the bid non-responsive. Performance Time: The project is a single-phase project and is to be complete within 90 calendar days from the Notice to Proceed. Liquidated damages apply to this project per the Supplementary Conditions.

Division 01 -	General Requirements, Special Procedures, Environmental Procedures.
Division 02 -	Existing Conditions, Environmental Assessment, Hazardous Material Assessment, Site Remediation, Asbestos Remediation.