FY 21/22 Pavement Rehabilitation Project

The work includes, but is not necessarily limited to, the furnishing of all labor, materials, equipment, and services necessary for, and reasonably incidental to paving and signing & striping, as shown or indicated in the Drawings and Specifications. The project is located at various streets within City of Seaside, Monterey County. Upon written request of the Contractor, the Engineer will add one day to the contract completion date for each working day that in the judgment of the Engineer work cannot be performed to the specifications herein due to inclement weather conditions. The Contractor shall submit such delay request to the Engineer no later than 9:00 a.m. on the workday in question. Bidders are required to sign and submit the bid forms provided in the Proposal and Contract book. No bid will be considered unless it is made on a proposal form furnished by the City and is accompanied by a bid bond for ten percent (10%) of the bid amount. The successful bidder shall furnish a Labor and Materials Bond, a Performance Bond, and a Surety Bond. The successful bidder will be required to secure a City Business License before commencing work on the project and must possess a Class A General Contractors license or a combination of Class C-8 7 C-12 Licenses at the time the contract is awarded. The successful bidder shall furnish three separate bonds: a performance bond, a labor and materials bond and a surety bond. Each of the said bonds shall be executed in a sum equal to one hundred percent of the Contract price and issued by a bonding company with an A.M. Best rating of A- or better, or instrument of credit. The Contractor shall begin work within 15 calendar days after the Notice to Proceed has been issued by the City of Seaside. This work shall be diligently prosecuted to completion before the expiration of 65 WORKING DAYS beginning on the fifteenth calendar day after approval of the contract. The Contractor shall pay liquidated damages to the City of Seaside, the sum of $5,400 per day, for each and every calendar days delay in finishing the work in excess of the number of working days prescribed above. The City reserves the right to reject any or all bids and the right to waiver minor irregularities or informalities in any bid proposal.

Division 32 -	Exterior Improvements, Operation and Maintenance of Exterior Improvements.
Division 34 -	Transportation, Operation and Maintenance of Transportation.