Downtown Water System Improvements Phase 1

This project is located in Port St. Joe, Florida and includes construction of approximately 2,110 LF of 10 (PVC) watermain, 915 LF of 10 High Density Polyethylene (HDPE) pipe, and associated connections and services. Work shall be performed by both open cut and directional drilling methods. There will also be approximately 500 square yards of asphalt patches, sidewalk removal and replacement, and other restoration associated with this work to restore the alleys and roadways once the project is complete. The completion date for this project will be 120 days for Substantial Completion and 150 days for Final Completion from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $500.00 per day.The City of Port St. Joe is an Equal Opportunity, Affirmative Action, Drug Free Work Place Employer and encourages the participation of minority and women-owned business. The City of Port St. Joe reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in their best interest. All bids shall remain firm for a period of sixty days after the opening. All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida.If you have any questions, please contact Josh Baxley in writing at jbaxley@dewberry.com by May 24,2023.

Division 33 -

Utilities, Instrumentation and Control for Utilities, Water Utilities, Water Utility Distribution Piping, Water Utility Distribution Equipment, Disinfecting of Water Utility Distribution, Water Utility Storage Tanks.