Ashville High School and Steele Jr. High School Cafeteria Renovations

**As of March 27, 2023, bids received were rejected as they were over the budget. No definite date for a rebid.** A. The Work of Project is defined by the Contract Documents and includes, but is not limited to, the following: 1. Ashville High School a. Renovation of existing kitchen and serving area and construction of 2500 SF Addition. 2. Steele Jr High School a. Minor renovation of existing kitchen and 275 SF Addition. B. Type of Contract: 1. Project will be constructed under a single prime contract A cashier's check or bid bond payable to St. Clair County Schools in an amount not less than five (5) percent of the amount of the bid, but in no event more than $10,000, must accompany the bidder's proposal. Performance and Payment Bonds and evidence of insurance required in the bid documents will be required at the signing of the Contract. Bid bonds are to be issued by an acceptable bonding company licensed to do business in the State, with a Power of Attorney, to confess judgment thereon, with the understanding that it shall guarantee that the bidder shall not withdraw his bid for the guarantee period of sixty (60) days after the scheduled closing time for the receipt of bids; that if his bid is accepted, he will enter into a formal contract with the Owner, and that in the event of a withdrawal of said bid within said period, or the failure to enter into said contract within the time specified, the bidder shall be liable to the Owner for the full amount of the bid guarantee as liquidated damages and not as a forfeit or as a penalty. The bid bond and certified checks on unsuccessful bidders will be returned upon awarding the contract or rejection of all bids, in no event, later than the number of days in the guarantee period from the opening of proposals. That of the successful bidder will be returned when formal contract and bonds are accepted and approved. Bids must be submitted on proposal forms furnished by the Architect or copies thereof. All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama, 1975, and must show evidence of license before bidding or bid will not be received or considered by the Architect; the bidder shall show such evidence by clearly displaying his or her current license number on the outside of the sealed envelope in which the proposal is delivered. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owner's judgment, the best interests of the Owner will thereby be promoted. Any questions concerning the pre-bid conference shall be directed to the Architect. Nonresident bidders must accompany any written bid documents with a written opinion of an attorney at law licensed to practice law in such nonresident bidder's state of domicile, as to the preferences, if any or none, granted by the law of that state to its own business entities whose principal places of business are in that state in the letting of any or all public contracts. Drawings and Specifications may be examined at the office of the Architect, Ward Scott Morris Architecture, Inc., 1606 Paul Bryant Drive, Tuscaloosa, Alabama, and TuscaBlue, 2806 Greensboro Avenue, Tuscaloosa, Alabama. Other sets for contractors, and sets for dealers, may be obtained with the same deposit, which will be refunded as above, less cost of printing, reproduction, handling, and distribution.

Division 03 -	Concrete, Concrete Forming, Concrete Reinforcing, Cast-in-Place Concrete.
Division 04 -	Masonry, Unit Masonry.
Division 05 -	Metals, Structural Metal Framing, Steel Joist Framing, Metal Fabrications.
Division 06 -	Wood, Plastics, and Composites, Rough Carpentry, Finish Carpentry, Millwork.
Division 07 -	Thermal and Moisture Protection, Dampproofing and Waterproofing, Thermal Protection, Weather Barriers.
Division 08 -	Openings, Doors and Frames, Metal Doors and Frames, Specialty Doors and Frames, Entrances and Storefronts, Windows, Mirrors, Vents.
Division 09 -	Finishes, Plaster and Gypsum Board, Tiling, Acoustical Ceilings, Flooring, Resilient Flooring, Carpeting, Painting, Exterior Painting, Interior Painting.
Division 10 -	Specialties, Visual Display Units, Chalkboards, Markerboards, Tackboards, Signage, Compartments and Cubicles, Toilet Compartments, Shower and Dressing Compartments, Fire Protection Specialties, Fire Protection Cabinets, Fire Extinguishers, Lockers, Flagpoles.
Division 11 -	Equipment, Refrigerated Display Equipment, Foodservice Equipment, Foodservice Storage Equipment, Refrigerated Food Storage Cases, Walk-In Coolers, Foodservice Shelving, Food Preparation Equipment, Food Cooking Equipment, Food Dispensing Equipment, Service Line Equipment, Soda Fountain Equipment, Ice Machines, Cleaning and Disposal Equipment, Educational and Scientific Equipment, Library Equipment, Audio-Visual Equipment, Laboratory Equipment, Athletic and Recreational Equipment.
Division 12 -	Furnishings, Window Treatments, Casework, Countertops, Furnishing Accessories, Waste Receptacles, Rugs and Mats, Entrance Floor Mats and Frames, Furniture, Multiple Seating, Site Furnishings, Trash and Litter Receptacles.
Division 21 -	Fire Suppression, Instrumentation and Control for Fire-Suppression Systems, Fire-Extinguishing Systems.
Division 22 -	Plumbing, Instrumentation and Control for Plumbing, Plumbing Piping, Facility Water Distribution, Facility Sanitary Sewerage, Facility Storm Drainage, Plumbing Equipment, Plumbing Fixtures, Commercial Plumbing Fixtures, Drinking Fountains and Water Coolers, Drinking Fountains.
Division 23 -	Heating, Ventilating, and Air Conditioning (HVAC), HVAC Insulation, Instrumentation and Control for HVAC, HVAC Air Distribution, Ventilation Hoods, Commercial-Kitchen Hoods.
Division 26 -	Electrical, Instrumentation and Control for Electrical Systems, Power Distribution Units, Lighting, Interior Lighting, Emergency Lighting, Exit Signs, Exterior Lighting, Lighting Poles and Standards, Parking Lighting.
Division 27 -	Communications, Structured Cabling, Data Communications, Voice Communications, Audio-Video Communications, Distributed Audio-Video Communications Systems, Paging Systems, Public Address Systems.
Division 28 -	Electronic Safety and Security, Electronic Access Control and Intrusion Detection, Electronic Detection and Alarm, Fire Detection and Alarm.
Division 31 -	Earthwork, Site Clearing, Grading, Excavation and Fill, Soil Treatment.
Division 32 -	Exterior Improvements, Bases, Ballasts, and Paving, Flexible Paving, Asphalt Paving, Rigid Paving, Concrete Paving, Curbs, Gutters, Sidewalks, and Driveways, Paving Specialties, Parking Bumpers, Speed Bumps, Pavement Markings, Athletic and Recreational Surfacing, Fences and Gates, Irrigation, Planting, Turf and Grasses.
Division 33 -	Utilities, Water Utilities, Sanitary Sewerage Utilities, Storm Drainage Utilities, Electrical Utilities.