Cullman Primary School New Outdoor Learning Center

As of February 14, 2024, this project has not yet been awarded. A timeline for award has not yet been established. A cashier's check or bid bond payable to Cullman City Schools in an amount not less than five (5) percent of the amount of the bid, but in no event more than $10,000, must accompany the bidder's proposal. Performance and Payment Bonds and evidence of insurance required in the bid documents will be required at the signing of the Contract. Other sets for contractors, and sets for dealers, may be obtained with the same deposit, which will be refunded as above, less cost of printing, reproduction, handling, and distribution. Bid bonds are to be issued by an acceptable bonding company licensed to do business in the State, with a Power of Attorney, to confess judgment thereon, with the understanding that it shall guarantee that the bidder shall not withdraw his bid for the guarantee period of sixty (60) days after the scheduled closing time for the receipt of bids; that if his bid is accepted, he will enter into a formal contract with the Owner, and that in the event of a withdrawal of said bid within said period, or the failure to enter into said contract within the time specified, the bidder shall be liable to the Owner for the full amount of the bid guarantee as liquidated damages and not as a forfeit or as a penalty. The bid bond and certified checks on unsuccessful bidders will be returned upon awarding the contract or rejection of all bids, in no event, later than the number of days in the guarantee period from the opening of proposals. That of the successful bidder will be returned when formal contract and bonds are accepted and approved. Bids must be submitted on proposal forms furnished by the Architect or copies thereof. All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama, 1975, and must show evidence of license before bidding or bid will not be received or considered by the Architect; the bidder shall show such evidence by clearly displaying his or her current license number on the outside of the sealed envelope in which the proposal is delivered. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owner's judgment, the best interests of the Owner will thereby be promoted. The bidder's company employee attending the pre-bid conference shall have qualifications and experience with the construction to be performed within this project. Any questions concerning the pre-bid conference shall be directed to the Architect. Nonresident bidders must accompany any written bid documents with a written opinion of an attorney at law licensed to practice law in such nonresident bidder's state of domicile, as to the preferences, if any or none, granted by the law of that state to its own business entities whose principal places of business are in that state in the letting of any or all public contracts. Drawings and Specifications may be examined at the office of the Architect, Ward Scott Architecture, Inc., 1300 Meridian Street North Suite 7, Huntsville, Alabama, and TuscaBlue, 2806 Greensboro Avenue, Tuscaloosa, Alabama.

Division 03 -	Concrete, Concrete Forming and Accessories, Cast-in-Place Concrete, Precast Concrete.
Division 04 -	Masonry, Unit Masonry.
Division 05 -	Metals.
Division 06 -	Wood, Plastics, and Composites, Rough Carpentry, Finish Carpentry.
Division 07 -	Thermal and Moisture Protection, Dampproofing and Waterproofing, Thermal Protection.
Division 08 -	Openings, Doors and Frames, Specialty Doors and Frames, Entrances, Storefronts, and Curtain Walls, Windows, Hardware.
Division 09 -	Finishes, Plaster and Gypsum Board, Tiling, Ceilings, Resilient Flooring, Carpeting, Painting.
Division 10 -	Specialties, Visual Display Units, Chalkboards, Markerboards, Tackboards, Signage, Compartments and Cubicles, Toilet, Bath, and Laundry Accessories, Toilet Accessories, Emergency Aid Specialties, Fire Protection Specialties, Lockers, Flagpoles.
Division 11 -	Equipment, Foodservice Equipment, Foodservice Storage Equipment, Food Preparation Equipment, Food Delivery Carts and Conveyors, Food Cooking Equipment, Food Dispensing Equipment, Ice Machines, Educational and Scientific Equipment, Audio-Visual Equipment, Play Field Equipment and Structures.
Division 12 -	Furnishings, Casework, Countertops, Office Furniture, Institutional Furniture, Classroom Furniture.
Division 21 -	Fire Suppression.
Division 22 -	Plumbing, Common Work Results for Plumbing, Plumbing Piping, Plumbing Equipment, Plumbing Fixtures, Drinking Fountains and Water Coolers.
Division 23 -	Heating, Ventilating, and Air Conditioning (HVAC), Common Work Results for HVAC, Instrumentation and Control for HVAC, HVAC Air Distribution, Ventilation Hoods, Commercial-Kitchen Hoods.
Division 25 -	Integrated Automation.
Division 26 -	Electrical, Instrumentation and Control for Electrical Systems, Lighting, Interior Lighting, Emergency Lighting, Exit Signs, Exterior Lighting.
Division 27 -	Communications, Common Work Results for Communications, Structured Cabling, Voice Communications, Audio-Video Communications, Audio-Video Systems, Integrated Audio-Video Systems and Equipment, Integrated Audio-Video Systems and Equipment for Classrooms, Distributed Communications and Monitoring Systems.
Division 28 -	Electronic Safety and Security, Common Work Results for Electronic Safety and Security, Electronic Access Control and Intrusion Detection, Fire Detection and Alarm.
Division 31 -	Earthwork, Common Work Results for Earthwork, Grading, Earthwork Methods, Soil Treatment.
Division 32 -	Exterior Improvements, Flexible Paving, Rigid Paving, Fences and Gates, Irrigation, Planting, Turf and Grasses.
Division 33 -	Utilities, Water Utilities, Sanitary Sewerage Utilities, Storm Drainage Utilities, Electrical Utilities, Communications Utilities.