Water Supply Plant - Phase 1 to Serve Brazoria County Municipal Utility District No. 87

Bid security in the form of bid bond, certified check or cashier's check payable to D.R. Horton - Texas, LLC on behalf of Brazoria County Municipal Utility District No. 87 in an amount not less than five percent (5%) of the Bid submitted, must accompany each Bid. The requirements of Subchapter J, Chapter 552, Government Code, may apply to this Bid and/or Contract and bidder/contractor agrees that the Contract can be terminated if the bidder/contractor knowingly or intentionally fails to comply with a requirement of that subchapter. Bidder/Contractor declares that it has not received from a governmental body a notice of noncompliance with a provision of Subchapter J, Chapter 552, Texas Government Code, or, if such notice has been received, bidder/contractor has taken adequate steps to ensure future compliance with such subchapter and has provided or upon request will provide documentation of same. D.R. Horton - Texas, LLC on behalf of Brazoria County Municipal Utility District No. 87 reserves the right to reject any and all bids. The Successful Bidder, if any, will be the responsible Bidder which in the Board's judgment will be most advantageous to the District and result in the best and most economical completion of the Project. (Texas Water Code 49.273) Completion Date: 360 Calendar Days.

Division 22 -

Plumbing, Common Work Results for Plumbing.