Replace Emergency Power and Main Switchgear

AWARD NUMBER* 36C26222C0174 AWARD AMOUNT* $10,221,727.00 LINE ITEM NUMBER Main Base Bid AWARD DATE (MM-DD-YYYY) * 08-31-2022 AWARDEE NAME* SHORE - HERMAN JV CONTRACTOR'S UEI MQB4RF9EJQ28 AWARDEE ADDRESS LINE 1* AWARDEE ADDRESS LINE 2* AWARDEE ADDRESS LINE 3* 2506 MARKET ST AWARDEE ADDRESS LINE 4* AWARDEE CITY SAN DIEGO AWARDEE STATE CA AWARDEE ZIP CODE 92102 Construction Services for the Department of Veterans Affairs, Loma Linda Healthcare System (VALLHS) Location: 11201 Benton Street, Loma Linda, CA 92357 Project Title: Emergency Generator Farm and Switchgear Upgrades Project Number: 605-19-400 Applicable NAICS Code: 236220 Small Business Size Standard - $39.5 M IAW VAAR 836.204 - Disclosure of Magnitude for the VA project: Between $5,000,000 and $10,000,000. Estimated Completion Time: Two Hundred Twenty-Four (224) Calendar Days Davis-Bacon Act Wage Determination applicable to the project: General Decision Number, CA20220026 04/01/2022 This contract will be awarded in accordance with FAR Part 14 -- Sealed Bidding. BID BOND, PAYMENT BOND & PERFORMANCE BOND ARE REQUIRED FOR THIS PROJECT. THIS PROCUREMENT IS 100% SET ASIDE FOR SERVICE-DISABLED VETERAN OWNED SMALL BUSINESS (SDVOSB) IN ACCORDANCE WITH PUBLIC LAW (PL) 109-461, 38 UNITED STATES CODE (USC), SECTION 8127 TO BE ELIGIBLE TO PARTICIPATE IN THIS PROCUREMENT. GENERAL INTENTION To provide construction services for Emergency Generator Farm and Switchgear Upgrades - Project 605-19-400 as required by the drawings and specifications attached. SITE VISIT Bidders are urged and encouraged to inspect the site where services are to be performed and to satisfy themselves regarding all general and local conditions that may affect the cost of performing these services. In no event shall failure to inspect the site constitute grounds for a claim after contract award. Interested contractors are highly encouraged to attend the pre-bid conference and site walk. Follow and VHA COVID-19 guidelines at all times. MASKS ARE REQUIRED inside at the VA Loma Linda Healthcare System. PRE-BID CONFERENCE: 11:00 a.m. (PST), June 2, 2022 in conference room no. MD-05D, FMS Building Annex, 11201 Benton Street, Loma Linda, CA 92357. PRE-BID SITE WALK will commence after the Pre-bid conference. Attendance is not mandatory; however, all bidders are strongly encouraged to attend. REQUESTS FOR INFORMATION (RFI): To obtain clarifications and/or additional information concerning the contract requirements, drawings, or specifications, submit a written RFI on Attachment D - RFI Form via email to maria.cruz-thompson@va.gov. The deadline for submission of RFIs for this solicitation is 2:00 p.m. (PST) Long Beach, CA, June 9, 2022. Subject Line of the email shall read: "RFIs, 36C26222B0005, 605-19-400, YOUR COMPANY NAME". No questions will be answered after this date/time unless determined to be in the best interest of the Government as determined by the Contracting Officer. Telephone RFIs will not be accepted or returned. RFI responses will be posted no later than close business, June 16, 2022. The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 224 days after receipt of notice to proceed. The time stated for completion shall include final cleanup of the premises. The completion date is based on the assumption that the successful offeror will receive the notice to proceed by 08/01/2022. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer. *The value for this project is based on a financial range. The value is listed as the highest possible cost from the range provided by a stakeholder or official project document.

Division 02 -	Existing Conditions, Subsurface Investigation.
Division 03 -	Concrete, Concrete Forming, Cast-in-Place Concrete, Precast Concrete.
Division 04 -	Masonry, Unit Masonry.
Division 05 -	Metals, Structural Metal Framing, Metal Joists, Metal Support Assemblies, Healthcare Metal Supports.
Division 06 -	Wood, Plastics, and Composites, Rough Carpentry, Finish Carpentry, Architectural Woodwork.
Division 07 -	Thermal and Moisture Protection, Dampproofing and Waterproofing, Thermal Protection, Thermal Insulation, Weather Barriers.
Division 08 -	Openings, Doors and Frames, Metal Doors and Frames, Wood Doors, Plastic Doors, Specialty Doors and Frames, Entrances, Storefronts, and Curtain Walls, Entrances and Storefronts, Curtain Wall and Glazed Assemblies, Windows, Hardware, Louvers and Vents.
Division 09 -	Finishes, Plaster and Gypsum Board, Tiling, Acoustical Ceilings, Flooring, Resilient Flooring, Carpeting, Acoustic Treatment, Painting.
Division 10 -	Specialties, Visual Display Units, Signage, Compartments and Cubicles, Toilet Compartments, Partitions, Service Walls, Patient Bed Service Walls, Wall and Door Protection, Toilet, Bath, and Laundry Accessories, Fire Protection Specialties, Fire Protection Cabinets, Fire Extinguishers, Storage Assemblies, Protective Covers, Flagpoles.
Division 11 -	Equipment, Mercantile and Service Equipment, Vending Equipment, Foodservice Equipment, Ice Machines, Cleaning and Disposal Equipment, Healthcare Equipment, Medical Sterilizing Equipment, Examination and Treatment Equipment, Patient Care Equipment, Operating Room Equipment, Solid Waste Handling Equipment.
Division 12 -	Furnishings, Window Treatments, Window Blinds, Casework, Furniture, Office Furniture, Seating, Institutional Furniture, Healthcare Furniture, Multiple Seating.
Division 13 -	Special Construction, Radiation Protection.
Division 14 -	Conveying Equipment.
Division 21 -	Fire Suppression, Fire-Suppression Sprinkler Systems, Fire-Extinguishing Systems.
Division 22 -	Plumbing, Instrumentation and Control for Plumbing, Plumbing Piping, Facility Water Distribution, Facility Sanitary Sewerage, Facility Storm Drainage, Plumbing Equipment, Plumbing Fixtures, Healthcare Plumbing Fixtures, Drinking Fountains and Water Coolers, Gas and Vacuum Systems for Laboratory and Healthcare Facilities, Compressed-Air Systems for Laboratory and Healthcare Facilities, Vacuum Systems for Laboratory and Healthcare Facilities, Gas Systems for Laboratory and Healthcare Facilities, Chemical-Waste Systems for Laboratory and Healthcare Facilities, Processed Water Systems for Laboratory and Healthcare Facilities.
Division 23 -	Heating, Ventilating, and Air Conditioning (HVAC), Instrumentation and Control for HVAC, HVAC Piping and Pumps, HVAC Air Distribution.
Division 25 -	Integrated Automation.
Division 26 -	Electrical, Instrumentation and Control for Electrical Systems, Substations, Interior Lighting, Emergency Lighting, Exit Signs, Special Purpose Lighting, Healthcare Lighting, Exterior Lighting.
Division 27 -	Communications, Structured Cabling, Data Communications, Voice Communications, Audio-Video Communications, Distributed Audio-Video Communications Systems, Paging Systems, Public Address Systems, Intercommunications and Program Systems, Healthcare Intercommunications and Program Systems, Healthcare Communications and Monitoring Systems.
Division 28 -	Electronic Safety and Security, Electronic Access Control and Intrusion Detection, Electronic Surveillance, Fire Detection and Alarm, Radiation Detection and Alarm.
Division 31 -	Earthwork, Site Clearing, Grading, Soil Treatment.
Division 32 -	Exterior Improvements, Bases, Ballasts, and Paving, Flexible Paving, Asphalt Paving, Rigid Paving, Concrete Paving, Curbs, Gutters, Sidewalks, and Driveways, Paving Specialties, Parking Bumpers, Pavement Markings, Fences and Gates, Planting Irrigation, Planting, Turf and Grasses.
Division 33 -	Utilities, Water Utilities, Sanitary Sewerage Utilities, Storm Drainage Utilities.