Fire Station 2 Reconstruction and Training Field Upgrades

Consultants are advised that the capacity to initiate and coordinate all CMAR services in a timely and efficient manner is a significant factor. Respondents who cannot meet this objective will be automatically eliminated from further consideration. This project shall include, but is not limited to: 1) Preconstruction Services: a. The CMAR will work with the City and Architect firm and regularly attend meetings to establish a project approach and consult with the Project Team on building materials, systems and equipment. b. Provide input to help prepare and make updates to the project schedule along with identify and communicate critical path and long lead items. c. Provide a thorough constructability review and provide comments during design phase. d. Provide construction estimates for each phase of design with written quotes from qualified subcontractors under competitive conditions which will be open record to the City and Architect. e. Pricing services. f. Establish a GMP and construction schedule based on complete Construction Documents. Include 5% Owner Contingency in GMP for sole use of the Owner. Any savings to be returned to the City. g. Publicly advertise and receive proposals from qualified subcontractors. The City and Architect will review the advertisement and receipt of bids and final approval of subcontractors will be determined collectively with the Project Team. 2) Construction Services: a. The CMAR will manage and supervise the construction of the work and provide a complete project per the Contract Documents prepared by the Architect. b. Attend regular meetings with the Project Team. c. Provide regular construction schedule updates with monthly payment applications. d. Prepare detailed Cost Log to be updated for each OAC meeting indicating contingency balance, additional items requested with cost estimates for each item and any cost savings. e. Maintain and submit Daily Reports to the City and Architect including weather, work activities, number of workers, list of subcontractors working, critical path activities impacted and identify any safety concerns/issues. f. Provide all close-out work (as-built documents, certifications, etc.)

Division 03 -	Concrete, Concrete Forming, Cast-in-Place Concrete.
Division 04 -	Masonry, Unit Masonry.
Division 05 -	Metals, Structural Metal Framing.
Division 06 -	Wood, Plastics, and Composites, Rough Carpentry, Finish Carpentry.
Division 07 -	Thermal and Moisture Protection, Dampproofing and Waterproofing, Thermal Protection, Weather Barriers.
Division 08 -	Openings, Metal Doors and Frames, Wood Doors, Plastic Doors, Specialty Doors and Frames, Panel Doors, Multi-Leaf Vertical Lift Doors.
Division 09 -	Finishes, Plaster and Gypsum Board, Tiling, Flooring, Acoustic Treatment, Painting, High-Performance Coatings.
Division 10 -	Specialties, Signage, Compartments and Cubicles, Toilet Compartments, Shower and Dressing Compartments, Toilet, Bath, and Laundry Accessories, Emergency Aid Specialties, Fire Protection Specialties, Lockers, Wardrobe and Closet Specialties, Flagpoles, Flags and Banners.
Division 11 -	Equipment, Unit Kitchens.
Division 12 -	Furnishings, Countertops, Rugs and Mats.
Division 14 -	Conveying Equipment, Slide Pole Systems, Firehouse Slide Poles.
Division 21 -	Fire Suppression, Facility Fire-Suppression Water-Service Piping, Fire-Department Connections, Fire Pumps.
Division 22 -	Plumbing, Instrumentation and Control for Plumbing, Facility Water Distribution, Facility Storm Drainage, Plumbing Equipment, Plumbing Fixtures, Emergency Plumbing Fixtures, Drinking Fountains and Water Coolers.
Division 23 -	Heating, Ventilating, and Air Conditioning (HVAC), Instrumentation and Control for HVAC, HVAC Piping and Pumps, HVAC Air Distribution.
Division 26 -	Electrical, Power Distribution Units, Interior Lighting, Emergency Lighting, Exit Signs, Exterior Lighting.
Division 27 -	Communications, Structured Cabling, Call Management, Distributed Audio-Video Communications Systems.
Division 28 -	Electronic Safety and Security, Electronic Detection and Alarm, Fire Detection and Alarm.
Division 31 -	Earthwork, Clearing and Grubbing, Grading, Soil Treatment.
Division 32 -	Exterior Improvements, Bases, Ballasts, and Paving, Flexible Paving, Asphalt Paving, Rigid Paving, Concrete Paving, Curbs, Gutters, Sidewalks, and Driveways.
Division 33 -	Utilities, Water Utilities, Sanitary Sewerage Utilities, Storm Drainage Utilities.