Repair UST Components (BLDG 4390 TLS & Associated Programming)

Project No.: 7065834 LOCATION The work is located at MCAS Cherry Point building 4390, approximately as indicated. The exact location will be shown by the Contracting Officer. (Clauses incorporated in Base Contract apply to this solicitation) Title: Repair UST Components (BLDG 4390 TLS & Associated Programming) NAICS Code and Standard Size: 238220, Plumbing, Heating, and Air-Conditioning Contractors, 16.5 Million Contract Completion Date: All work shall be completed within 180 calendar days after award Estimated Cost Range: Between $25,000 and $100,000. Wage Determination: General Decision NC20230065 01/06/2023 Liquidated Damages: $32 per calendar day of delay Basis for Award: Lowest Price Proposal Acceptance Period: 90 calendar days after receipt of offers Bond Requirements: Bid bonds are required in accordance with FAR 28-101-4. An electronic copy of your bid bond must be submitted with your proposal. An electronic copy of your bid bond will be requested from the apparent low upon confirmation of their price and must be submitted to the FEAD office within one (1) week from time of request. Failure to submit an electronic copy of your bid bond with your proposal will result in your proposal being deemed nonresponsive and your proposal removed from consideration. In accordance with FAR Clause 52.228-15 Performance and Payment Bonds--Construction and FAR Clause 52.228-13 Alternate Payment Protections, Payment and/or performance bond(s) will be requested at the time of award. BONDS TO BE PROVIDED ELECTRONICALLY, SEALS MUST BE VISIBLE o No bonds are required for proposals less than $40K. o Proposals valued at $40K and greater will require a payment bond only. o Proposals valued at $150K and greater will require a bid bond, a payment bond, and a performance bond. FAR Clause 52.222-55, Minimum Wages for Contractor Workers Under Executive Order 14026 is applicable for this solicitation. FAR Clause 52.222-55, Minimum Wages for Contractor Workers Under Executive Order 14026 is applicable for this solicitation. DFARS 252.225-7059 Prohibition on Certain Procurements from the Xinjiang Uyghur Autonomous Region--Certification, which includes a certification requirement stated below. DFARS 252.225-7060, Prohibition on Certain Procurements from the Xinjiang Uyghur Autonomous Region, which prohibits contractors from providing any products mined, produced, or manufactured wholly or in part by forced labor from XUAR or from an entity that has used labor from within or transferred from XUAR as part of any forced labor programs. Please either return an email or add the certification statement on your proposals stating the following: "Certification from (Please enter your company name here) that you have made a good faith effort to determine that forced labor from XUAR was not or will not be used in the performance of a contract resulting from this solicitation RFIs must be submitted email addresses above. The cut off for RFIs is 30 May 2023 by 0900 in order to process all inquiries by the proposal due date. *The value for this project is based on a financial range. The value is listed as the highest possible cost from the range provided by a stakeholder or official project document.

Division 23 -

Heating, Ventilating, and Air Conditioning (HVAC), Instrumentation and Control for HVAC, HVAC Air Distribution, Central HVAC Equipment.