Lud Drexler Dump Station

Type of Contract: Construction, Firm-Fixed Price (FFP) County: Twin Falls County, Idaho Type of Construction: Heavy Magnitude: Between $25,000 and $100,000 NAICS: 237990 Size Standard: $39.5 Million Set-Aside: Total Small Business Period of Performance: 09/06/2022 to 10/15/2022 General (a) The Bureau of Land Management (BLM) is seeking quotations for construction services as attached in the accompanying statement of work. The BLM intends to conduct this acquisition by use of simplified acquisition procedures in accordance with FAR Part 13. A single contract award will be made to the Offeror that submits a quotation that has been determined to be the lowest price reasonable offeror. (b) The Government will not award any contract if the resulting contract would not represent a "best value" to the Government. (c) To assure timely and equitable evaluation of quotations, respondents are cautioned to strictly comply with all instructions within this solicitation to ensure submission of a complete quotation. Offerors are required to meet all solicitation requirements, including terms and conditions, representations and certifications, and technical requirements. Failure to adhere to quotation requirements, at the time of submission, may result in the quotation being unacceptable to the Government and eliminated from consideration for award. It is the responsibility of offerors to ensure their quote is received by the recipient and by the due date and time. (d) Offerors are cautioned to submit adequate information to enable the Government to fully ascertain each offeror's capability to perform the requirements in accordance with the requirements of the request for quotation (RFQ). (e) If a respondent believes that requirements in these instructions contain an error, omission, or are otherwise flawed, the respondent shall immediately notify the Contracting Officer in writing (email is the preferred method) with supporting rationale by the question deadline specified on the cover page of this document. (f) This RFQ does not commit the Government to any costs incurred in the preparation and submission of a quote or for any other costs incurred by any firm submitting a quote in response to this solicitation. Note specifically that the Offeror will not be participating in a sealed bid procurement process under this acquisition method. Issuance of this RFQ does not constitute an award commitment on the part of the Government. (g) Quotation must be valid for a minimum of 60 days. (h) Respondents must complete the System for Award Management (SAM) at https://sam.gov (previously ORCA and CCR). The Government will obtain respondent representations and certifications through this system. (i) Award is subject to and based on the availability of funds. This project is currently funded based upon an independent cost estimate. (j) Including all other factors, to qualify for award, a respondent must be determined responsible in accordance with Federal Acquisition Regulation Part 9. (k) Respondents shall not contact any government personnel related to this requirement other than the Contracting Officer. (l) All questions should be emailed directly to the Contracting Officer. Only written RFI's will be considered and responded to by the Government. BLM responses to RFIs will be posted as an amendment to the solicitation. (m) The successful Offeror shall submit appropriate Performance and Payment Bonds in accordance with clause 52.228-1 or Alternative Payment Protection in accordance with clause 52.228-13 within 10 days of contract award. Commencement, Prosecution, and Completion of Work (Apr 1984) The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 30 days after receipt of Notice to Procced. *The time stated for completion shall include final cleanup of the premises. *The Government recognizes that seasonal climatic conditions may occur that restrict or prohibit normal construction activities. The anticipated length of the seasonal delay for this project is 0 days. This number of days has been included in calculating the stated period of performance. Therefore, the contract period of performance will not be extended due to normal seasonal weather delays. Submittal of Questions (if applicable) Offeror is to consolidate questions related to this solicitation and site visit in a Request for Information (RFI) formatted Word document. The RFI is to be emailed as an editable attachment to the Contracting Officer at pfort@blm.gov by the deadline on the cover page of this document with the subject line: 140L2622Q0039/ Lud Drexler Dump Station. *The value for this project is based on a financial range. The value is listed as the highest possible cost from the range provided by a stakeholder or official project document.

Division 03 -	Concrete.
Division 04 -	Masonry.
Division 05 -	Metals.
Division 06 -	Wood, Plastics, and Composites.
Division 07 -	Thermal and Moisture Protection.
Division 08 -	Openings.
Division 09 -	Finishes.
Division 10 -	Specialties, Signage, Toilet, Bath, and Laundry Accessories, Fire Protection Specialties, Fire Extinguishers, Storage Specialties.
Division 11 -	Equipment.
Division 12 -	Furnishings.
Division 14 -	Conveying Equipment, Scaffolding.
Division 21 -	Fire Suppression.
Division 22 -	Plumbing.
Division 23 -	Heating, Ventilating, and Air Conditioning (HVAC).
Division 26 -	Electrical.
Division 27 -	Communications, Data Communications, Voice Communications, Audio-Video Systems.
Division 28 -	Electronic Safety and Security.
Division 31 -	Earthwork.
Division 32 -	Exterior Improvements, Fences and Gates, Turf and Grasses.
Division 33 -	Utilities, Common Work Results for Utilities, Instrumentation and Control for Utilities, Water Utilities, Water Utility Distribution Piping, Water Utility Distribution Equipment, Water Utility Pumping Stations, Disinfecting of Water Utility Distribution, Water Utility Storage Tanks, Wastewater Utility Pumping Stations, Sanitary Utility Sewerage Force Mains.
Division 40 -	Process Integration, Water Process Piping.
Division 45 -	Industry-Specific Manufacturing Equipment.
Division 46 -	Water and Wastewater Equipment.