Stewart Street II SCOP

Site work and paving for a road / highway in Quincy, Florida. Completed plans call for site work for a road / highway; and for paving for a road / highway. The project will consist of milling and resurfacing Stewart Street from King Street South to US 90. Signing and striping will also be included within the scope. Completion date for this project will be 90 days from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $200.00 per day. Please indicate on the envelope that this is a sealed bid for the Stewart Street II SCOP Project. The Quincy City Council reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of The City of Quincy. If you have any questions, please contact Matthew Chester at (850) 674-3300 or MChester@Dewberry.com.

Division 01 -	General Requirements, Vehicular Access and Parking, Traffic Control, Temporary Barriers and Enclosures.
Division 32 -	Exterior Improvements, Flexible Paving, Asphalt Paving, Rigid Paving, Concrete Paving, Paving Specialties, Pavement Markings.
Division 33 -	Utilities, Storm Drainage Utilities, Storm Drainage Structures.