Electric Vehicle Charging Stations for Central Office

Ref. #: 2311-5440 The Housing Authority of the City of San Antonio, a/k/a Opportunity Home San Antonio and its affiliated entities (Opportunity Home) hereby invites qualified independent Respondents to submit bids for labor, materials and equipment to install eight (8) Level II dual port electric vehicle charging stations at Opportunity Home central office. Opportunity Home requires a Bid Guarantee for this bid in the amount of 5% of the Base Bid, which shall be submitted with the Bid Fee Sheet. Proposals without a Bid Guarantee will be rejected. Nonsurety Bid Guarantees must be in guaranteed funds such as Cashier's Check, Certified Check, Bank Draft, irrevocable letter of credit, or similar cash instrument. Performance Bond: The Contractor must provide Opportunity Home a 100% Performance Bond for total contract value, however, if the Contractor is unable to acquire the equitable bonding that is acceptable to Opportunity Home within ten (10) days of the signed contract, then the Contractor will be deemed in breach of contract. Payment Bond: The Contractor must provide Opportunity Home with a 100% Payment Bond for each Project Contract executed by Opportunity Home, however, if the Contractor is unable to acquire the equitable bonding that is acceptable to Opportunity Home within ten (10) days of the signed contract, then the Contractor will be deemed in breach of contract. Firm fixed contract for one (1) year with the option to extend up to four additioanls one (1) year periods at the sole discretion of Opportunity Home. For each day that performance under a resulting contract from this IFB is delayed beyond the time specified for completion, the successful Respondent shall be liable for liquidated damages in the amount of $100.00 per day. However, the timeframe for performance may be adjusted at Opportunity Home's discretion in writing and received by the successful Respondent prior to default under any resulting contract. Questions Due Date: Nov 20th 2023, 5:00 PM CST

Division 26 -

Electrical.