Fire Station 55 Roof Replacement

The City of Visalia expressly reserves the right to modify, or withdraw from, the process initiated and described herein. No rights shall be vested in any party, individual or entity by virtue of its preparation to participate in, or its participation in, such process. The City expressly reserves the right to modify, for any reason, the schedule and any provision contained herein. The City reserves to itself the selection of winning respondent(s), if any, in the exercise of its sole discretion. No binding commitment shall arise on the part of the City to any respondent under this Request for Bid until and unless the parties sign documents of agreement that become effective in accordance with their terms. Responses to this RFB, however, shall be held firm by Respondent for at least ninety (90) days. Tentative date of award date: August 2022. Contractor must be able to begin the work as described within this bid upon receipt of the City's Notice to Proceed. The Notice to Proceed shall be issued in writing by the Purchasing Department. The entire project must be completed within thirty (30) calendar days from the effective date of the Notice to Proceed, which will be issued in writing by the Purchasing Department. Prevailing Wages: Under the requirements of Labor Code section 1782 passed by SB7 and in compliance with City of Visalia Ordinance 2014-13, this public works project is subject to State prevailing wages as specified in the plans and specifications. 6. License Requirements: No bid will be accepted from a Contractor who is not duly licensed in accordance with the provisions of Chapter 9, Division III of the State of California Business and Professions Code and has a current C-39 Roofing License. See Section III for additional Department of Industrial Relations Requirements which apply to this project. Use of Subcontractors: Your proposal may include subcontractors and you should clearly delineate the responsibilities of each of those participants within your proposal. However, the City will recognize the party legally signing the Bid Proposal as prime contractor and contacting party, who, as such, will assume ultimate responsibility for ensuring compliance with the specifications, terms and conditions of the Invitation to Bid. Liquidated Damages: Five Hundred Dollars ($500) per day for each day the project is delayed beyond the agreed completion date of thirty (30) working days from the effective date of the Notice to Proceed.

Division 07 -

Thermal and Moisture Protection, Dampproofing and Waterproofing, Thermal Protection.