White City Well

This project includes the construction and development of one upper Floridian aquifer production well in White City, FL. The completion date for this project will be 120 days from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $1,000.00 per day. All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes. All questions must be submitted to Clay Smallwood, P.E. at csmallwood@gulfcounty-fl.gov. The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Gulf County. All questions about the meaning or intent of the Bidding Documents are to be submitted to Engineer in writing.

Division 03 -	Concrete.
Division 04 -	Masonry.
Division 05 -	Metals.
Division 06 -	Wood, Plastics, and Composites.
Division 07 -	Thermal and Moisture Protection.
Division 08 -	Openings.
Division 09 -	Finishes.
Division 10 -	Specialties, Signage, Toilet, Bath, and Laundry Accessories, Fire Protection Specialties, Fire Extinguishers, Storage Specialties.
Division 11 -	Equipment.
Division 12 -	Furnishings.
Division 14 -	Conveying Equipment, Scaffolding.
Division 21 -	Fire Suppression.
Division 22 -	Plumbing.
Division 23 -	Heating, Ventilating, and Air Conditioning (HVAC).
Division 26 -	Electrical.
Division 27 -	Communications, Data Communications, Voice Communications, Audio-Video Systems.
Division 28 -	Electronic Safety and Security.
Division 31 -	Earthwork.
Division 32 -	Exterior Improvements, Fences and Gates, Turf and Grasses.
Division 33 -	Utilities, Common Work Results for Utilities, Water Utility Distribution Equipment, Water Utility Pumping Stations, Wastewater Utility Pumping Stations, Sanitary Utility Sewerage Force Mains.
Division 40 -	Process Integration, Water Process Piping.
Division 45 -	Industry-Specific Manufacturing Equipment.
Division 46 -	Water and Wastewater Equipment.