Chattahoochee Smart Meter Project

The City of Chattahoochee Will Receive Sealed Bids From Any Qualified Person, Company or Corporation Interested in Constructing the Chattahoochee Smart Meter Project . This project shall consist of the installation of new water meters within the City of Chattahoochee. The work will include supplying and installing new smart meters with remote read capabilities. Completion date for these projects will be 90 days from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $200.00 per day. Please indicate on the envelope that this is a sealed bid for the CHATTAHOOCHEE SMART METER PROJECT . The City of Chattahoochee reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of the City of Chattahoochee. If you have any questions, please contact Matthew Chester via phone at (850) 674-3300 or email at MChester@Dewberry.com.

Division 11 -

Equipment, Operation and Maintenance of Equipment, Vehicle Service Equipment, Maintenance Equipment, Unit Kitchens, Residential Equipment, Residential Appliances, Agricultural Equipment.