Murfreesboro Fire Station #3 Renovations and Additions

The project includes interior renovation of the existing Fire Station #3 to include a new laundry/decontamination room and addition of 900sf to house new locker rooms and storage. The General Contractor shall provide a fully qualified superintendent that is a full-time employee of the General Contractor on site at ALL times when work on site is occurring. Question Submission Deadline:August 9, 2022, 2:00pm A cashier's check or Bid Bond payable to the City of Murfreesboro, in an amount not less than five (5) percent of the amount of the proposal, but in no event more than $10,000 must accompany the bid. Performance and Statutory Labor and Material Payment Bonds in the amount of 100% of the Contract Price will be required at the signing of the Contract.A cashier's check or Bid Bond payable to the City of Murfreesboro, in an amount not less than five (5) percent of the amount of the proposal, but in no event more than $10,000 must accompany the bid. Performance and Statutory Labor and Material Payment Bonds in the amount of 100% of the Contract Price will be required at the signing of the Contract. All questions relative to the Contract Documents shall be addressed to the Architect for clarification. All bidders must submit one electronic copy of their bid via OpenGov on proposal forms furnished by the City or copies thereof. All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of the Code of Tennessee and must show evidence of license before bidding or bid will not be received or considered by the Architect; the bidder shall show such evidence by clearly displaying his or her current license number on the Contractor's License document to be uploaded with the bid via OpenGov. The Owner reserves the right to reject any or all of the proposals and to waive technical errors if, in the Owner's judgment, the best interest of the owner will thereby be promoted. Performance time: The project is a single-phase project and is to be completed within 180 calendar days from Notice to Proceed. Liquidated damages apply to this project per the supplementary conditions.

Division 03 -	Concrete, Concrete Forming, Cast-in-Place Concrete.
Division 04 -	Masonry, Unit Masonry.
Division 05 -	Metals, Structural Metal Framing.
Division 06 -	Wood, Plastics, and Composites, Rough Carpentry, Finish Carpentry.
Division 07 -	Thermal and Moisture Protection, Dampproofing and Waterproofing, Thermal Protection, Weather Barriers.
Division 08 -	Openings, Metal Doors and Frames, Wood Doors, Plastic Doors, Specialty Doors and Frames, Panel Doors, Multi-Leaf Vertical Lift Doors.
Division 09 -	Finishes, Plaster and Gypsum Board, Tiling, Flooring, Acoustic Treatment, Painting, High-Performance Coatings.
Division 10 -	Specialties, Signage, Compartments and Cubicles, Toilet Compartments, Shower and Dressing Compartments, Toilet, Bath, and Laundry Accessories, Emergency Aid Specialties, Fire Protection Specialties, Lockers, Wardrobe and Closet Specialties, Flagpoles, Flags and Banners.
Division 11 -	Equipment, Unit Kitchens.
Division 12 -	Furnishings, Countertops, Rugs and Mats.
Division 14 -	Conveying Equipment, Slide Pole Systems, Firehouse Slide Poles.
Division 21 -	Fire Suppression, Facility Fire-Suppression Water-Service Piping, Fire-Department Connections, Fire Pumps.
Division 22 -	Plumbing, Instrumentation and Control for Plumbing, Facility Water Distribution, Facility Storm Drainage, Plumbing Equipment, Plumbing Fixtures, Emergency Plumbing Fixtures, Drinking Fountains and Water Coolers.
Division 23 -	Heating, Ventilating, and Air Conditioning (HVAC), Instrumentation and Control for HVAC, HVAC Piping and Pumps, HVAC Air Distribution.
Division 26 -	Electrical, Power Distribution Units, Interior Lighting, Emergency Lighting, Exit Signs, Exterior Lighting.
Division 27 -	Communications, Structured Cabling, Call Management, Distributed Audio-Video Communications Systems.
Division 28 -	Electronic Safety and Security, Electronic Detection and Alarm, Fire Detection and Alarm.
Division 31 -	Earthwork, Clearing and Grubbing, Grading, Soil Treatment.
Division 32 -	Exterior Improvements, Bases, Ballasts, and Paving, Flexible Paving, Asphalt Paving, Rigid Paving, Concrete Paving, Curbs, Gutters, Sidewalks, and Driveways.
Division 33 -	Utilities, Water Utilities, Sanitary Sewerage Utilities, Storm Drainage Utilities.